Section one: Contracting authority/entity
one.1) Name and addresses
Associated British Ports
25 Bedford Street, London, WC2E 9ES
London
WC2E 9ES
Country
United Kingdom
NUTS code
UK - United Kingdom
Internet address(es)
Main address
https://in-tendhost.co.uk/abp/aspx/Tenders/Current
Buyer's address
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
New Distribution Centre located at the Port of Cardiff
Reference number
2021/S 000-027744
two.1.2) Main CPV code
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
two.1.3) Type of contract
Works
two.1.4) Short description
Associated British Ports (ABP) intend to procure a Contractor to deliver the design and construction of a 11,000m2 distribution center comprising warehouse and office accommodation and associated external works (including but not limited to its associated civils, landscaping, car parking, service yard and van storage) on a site covering approximately 24 acres at the Port of Cardiff as further detailed within Appendix 1 of this PQQ document.
Section six. Complementary information
six.6) Original notice reference
Notice number: 2021/S 000-027744
Section seven. Changes
seven.1.2) Text to be corrected in the original notice
Section number
II.2.4
Place of text to be modified
Notice
Instead of
Text
II.2.4) Description of the procurementAssociated British Ports (ABP) intend to procure a Contractor to deliver the designand construction of a 11,000m2 distribution center comprising warehouse and officeaccommodation and associated external works (including but not limited to itsassociated civils, landscaping, car parking, service yard and van storage) on a sitecovering approximately 24 acres at the Port of Cardiff as further detailed withinAppendix 1 of this PQQ document. The overall duration of the design and constructionof the works, is to be 8 months. The start date is envisaged to be March 2022 whichwould result in completion of the whole of the works by October 2022. Whilst thestart and completion dates may move based on this procurement process, the overalldurations for the design and construction of the works will remain as 8 months. TheContract will include key dates and sectional completion dates including conditionsto be met for these dates as the Contractor will have to accommodate work (to beclearly defined in the scope and contract data part one) by others not employed byABP. ABP intend to engage with the successful bidder under the NEC 4 ECC OptionA form of contract with amendments which will include provisions for delaydamages. The successful Contractor is required to take on full responsibility for thedesign in its entirety including the design provided by the Client. The Contractor isto complete the design and construct the works. The total estimated contract valueis circa £25 million.
Read
Text
II.2.4) Description of the procurementAssociated British Ports (ABP) intend to procure a Contractor to deliver the designand construction of a 11,000m2 distribution center comprising warehouse and officeaccommodation and associated external works (including but not limited to itsassociated civils, landscaping, car parking, service yard and van storage) on a sitecovering approximately 24 acres at the Port of Cardiff as further detailed withinAppendix 1 of the PQQ document. The estimated duration for the design and construction of the works is 10 months.The Contract will include key dates and sectional completion dates including conditionsto be met for these dates as the Contractor will have to accommodate work (to beclearly defined in the scope and contract data part one) by others not employed byABP. ABP intend to engage with the successful bidder under the NEC 4 ECC OptionA form of contract with amendments which will include provisions for delaydamages. The successful Contractor is required to take on full responsibility for thedesign in its entirety including the design provided by the Client. The Contractor isto complete the design and construct the works.Organisations wishing to participate must submit a completed PQQ document by the 14th January 2022.
Section number
IV.2.2
Place of text to be modified
Notice
Instead of
Date
9 December 2021
Local time
12:00pm
Read
Date
14 January 2022
Local time
5:00pm
Section number
III.1.6
Place of text to be modified
Notice
Instead of
Text
III.1.6) Deposits and guarantees requiredPreviously blank - no entry made
Read
Text
III.1.6) Deposits and guarantees requiredThe utility may require a parent company/bank guarantee and/or performance bond (as appropriate) as a condition of any contract to be awarded
Section number
II.2.3
Place of text to be modified
Notice
Instead of
Text
Place of performance NUTS CodesUK - United Kingdom
Read
Text
Place of performance NUTS CodesUK L22 Cardiff
Section number
III.1.8
Place of text to be modified
Notice
Instead of
Text
III.1.8) Legal form to be taken by the group of economic operators to whom the contract is to be awardedPreviously blank - no entry
Read
Text
III.1.8) Legal form to be taken by the group of economic operators to whom the contract is to be awardedNo specific legal form is required at this stage. However, the utility reserves the right to require the successful contractor to take a specific legal form and/or assume joint and several liability if bidding on a consortium/subcontracting basis. This will be subject to discussion during the procurement process.
Section number
VI.4.1
Place of text to be modified
Notice
Instead of
Text
VI.4.1) Review bodyOfficial Name:Associated British PortsPostal Address: 25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountry:United KingdomE-mailprocurement@abports.co.uk
Read
Text
VI.4.1) Review bodyOfficial Name:High Court of JusticePostal Address: Royal Courts of Justice, StrandTown:LondonPostal Code:WC2A 2LLCountry:United Kingdom
Section number
VI.4.2
Place of text to be modified
Notice
Instead of
Text
VI.4.2) Body responsible for mediation procedureOfficial Name:Associated British PortsPostal Address:25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountryUnited KingdomE-mail:procurement@abports.co.uk
Read
Text
VI.4.2) Body responsible for mediation procedureBlank - no entry made
Section number
II.2.7
Place of text to be modified
Notice
Instead of
Text
II.2.7) Duration of the contract, framework agreement or dynamic purchasing systemDuration in months: 8
Read
Text
II.2.7) Duration of the contract, framework agreement or dynamic purchasing systemDuration in months: 10