Section one: Contracting authority
one.1) Name and addresses
Scape Procure Limited
2nd Floor, East West Building, 1 Tollhouse Hill
Nottingham
NG1 5AT
Contact
Nick Taylor
Telephone
+44 1159583200
Country
United Kingdom
Region code
UKF14 - Nottingham
National registration number
09955814
Internet address(es)
Main address
https://www.scape.co.uk/live-procurement
Buyer's address
one.2) Information about joint procurement
The contract is awarded by a central purchasing body
one.4) Type of the contracting authority
Body governed by public law
one.5) Main activity
Other activity
Scape is a public sector owned, built environment specialist supplier of framework solutions.
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
Scape Regional Construction Framework
Reference number
SCP008
two.1.2) Main CPV code
- 45000000 - Construction work
two.1.3) Type of contract
Works
two.1.4) Short description
Scape Procure Ltd (Scape) have established a framework agreement with a 4-year duration. Experienced contractors were invited to apply for one (1) of four (4) regions to undertake construction works and services as defined by the NUTS and CPV codes. Each region contains two (2) parallel Lots. Applications were welcomed from consortia, joint ventures etc. Such parties were required to form a single legal entity prior to contract award. A maximum of five (5) bidders were invited to ITT stage for each of the four (4) regions. One (1) contractor was appointed to each lot. This Framework Agreement will be accessible for use by public sector bodies and their statutory successors, corporations established, or a group of individuals appointed to act together as defined by Part 1 of the Public contracts Regulation 2015 or cited by name in Schedule 1 to the Public Contracts Regulations 2015 and online at: https://www.scape.co.uk/site-information/framework-usage-eligibility
two.1.6) Information about lots
This contract is divided into lots: Yes
two.1.7) Total value of the procurement (excluding VAT)
Value excluding VAT: £750,000,000
two.2) Description
two.2.1) Title
Lot 1 - North West
Lot No
1
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 45450000 - Other building completion work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKF24 - West Northamptonshire
- UKF11 - Derby
- UKF25 - North Northamptonshire
- UKF12 - East Derbyshire
- UKF22 - Leicestershire CC and Rutland
- UKF13 - South and West Derbyshire
- UKG24 - Staffordshire CC
- UKG13 - Warwickshire
- UKF2 - Leicestershire, Rutland and Northamptonshire
- UKF21 - Leicester
Main site or place of performance
West Northamptonshire,Derby,North Northamptonshire,East Derbyshire,Leicestershire CC and Rutland,South and West Derbyshire,Staffordshire CC,Warwickshire,Leicestershire, Rutland and Northamptonshire,Leicester
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments. All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP. Bidders applying for this Lot were required to have a minimum annual turnover of 25,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 2 - North West
Lot No
2
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 44200000 - Structural products
- 31100000 - Electric motors, generators and transformers
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 45450000 - Other building completion work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKF24 - West Northamptonshire
- UKF11 - Derby
- UKF25 - North Northamptonshire
- UKF12 - East Derbyshire
- UKF22 - Leicestershire CC and Rutland
- UKF13 - South and West Derbyshire
- UKG24 - Staffordshire CC
- UKG13 - Warwickshire
- UKF2 - Leicestershire, Rutland and Northamptonshire
- UKF21 - Leicester
Main site or place of performance
West Northamptonshire,Derby,North Northamptonshire,East Derbyshire,Leicestershire CC and Rutland,South and West Derbyshire,Staffordshire CC,Warwickshire,Leicestershire, Rutland and Northamptonshire,Leicester
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments. All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP. Bidders applying for this Lot were required to have a minimum annual turnover of 25,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 3 - North East
Lot No
3
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 45450000 - Other building completion work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKF22 - Leicestershire CC and Rutland
- UKF14 - Nottingham
- UKF15 - North Nottinghamshire
- UKF16 - South Nottinghamshire
- UKF30 - Lincolnshire
- UKF3 - Lincolnshire
- UKE13 - North and North East Lincolnshire
Main site or place of performance
Leicestershire CC and Rutland,Nottingham,North Nottinghamshire,South Nottinghamshire,Lincolnshire,Lincolnshire,North and North East Lincolnshire
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 25,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 4 - North East
Lot No
4
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45400000 - Building completion work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45450000 - Other building completion work
- 45410000 - Plastering work
- 45430000 - Floor and wall covering work
- 45420000 - Joinery and carpentry installation work
- 45440000 - Painting and glazing work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
- 71200000 - Architectural and related services
two.2.3) Place of performance
NUTS codes
- UKF22 - Leicestershire CC and Rutland
- UKF14 - Nottingham
- UKF15 - North Nottinghamshire
- UKF16 - South Nottinghamshire
- UKF30 - Lincolnshire
- UKF3 - Lincolnshire
- UKE13 - North and North East Lincolnshire
Main site or place of performance
Leicestershire CC and Rutland,Nottingham,North Nottinghamshire,South Nottinghamshire,Lincolnshire,Lincolnshire,North and North East Lincolnshire
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 25,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 5 - South West
Lot No
5
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45450000 - Other building completion work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71400000 - Urban planning and landscape architectural services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKH3 - Essex
- UKH2 - Bedfordshire and Hertfordshire
Main site or place of performance
Essex,Bedfordshire and Hertfordshire
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 10,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 6 - South West
Lot No
6
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45220000 - Engineering works and construction works
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 45450000 - Other building completion work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKH3 - Essex
- UKH2 - Bedfordshire and Hertfordshire
Main site or place of performance
Essex,Bedfordshire and Hertfordshire
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 10,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 7 - South East
Lot No
7
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 09330000 - Solar energy
- 50000000 - Repair and maintenance services
- 70000000 - Real estate services
- 71000000 - Architectural, construction, engineering and inspection services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 45450000 - Other building completion work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKH17 - Breckland and South Norfolk
- UKH12 - Cambridgeshire CC
- UKH11 - Peterborough
- UKH14 - Suffolk
- UKH16 - North and West Norfolk
- UKH15 - Norwich and East Norfolk
Main site or place of performance
Breckland and South Norfolk,Cambridgeshire CC,Peterborough,Suffolk,North and West Norfolk,Norwich and East Norfolk
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 10,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
two.2) Description
two.2.1) Title
Lot 8 - South East
Lot No
8
two.2.2) Additional CPV code(s)
- 45000000 - Construction work
- 09330000 - Solar energy
- 31100000 - Electric motors, generators and transformers
- 44200000 - Structural products
- 50000000 - Repair and maintenance services
- 71000000 - Architectural, construction, engineering and inspection services
- 70000000 - Real estate services
- 79000000 - Business services: law, marketing, consulting, recruitment, printing and security
- 44211100 - Modular and portable buildings
- 45100000 - Site preparation work
- 45110000 - Building demolition and wrecking work and earthmoving work
- 45120000 - Test drilling and boring work
- 45200000 - Works for complete or part construction and civil engineering work
- 45210000 - Building construction work
- 45211000 - Construction work for multi-dwelling buildings and individual houses
- 45212000 - Construction work for buildings relating to leisure, sports, culture, lodging and restaurants
- 45213000 - Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport
- 45214000 - Construction work for buildings relating to education and research
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
- 45216000 - Construction work for buildings relating to law and order or emergency services and for military buildings
- 45220000 - Engineering works and construction works
- 45230000 - Construction work for pipelines, communication and power lines, for highways, roads, airfields and railways; flatwork
- 45240000 - Construction work for water projects
- 45250000 - Construction works for plants, mining and manufacturing and for buildings relating to the oil and gas industry
- 45260000 - Roof works and other special trade construction works
- 45300000 - Building installation work
- 45310000 - Electrical installation work
- 45320000 - Insulation work
- 45330000 - Plumbing and sanitary works
- 45340000 - Fencing, railing and safety equipment installation work
- 45350000 - Mechanical installations
- 45400000 - Building completion work
- 45410000 - Plastering work
- 45450000 - Other building completion work
- 45420000 - Joinery and carpentry installation work
- 45430000 - Floor and wall covering work
- 45440000 - Painting and glazing work
- 50700000 - Repair and maintenance services of building installations
- 50800000 - Miscellaneous repair and maintenance services
- 70110000 - Development services of real estate
- 70111000 - Development of residential real estate
- 70112000 - Development of non-residential real estate
- 71200000 - Architectural and related services
- 71300000 - Engineering services
- 71314000 - Energy and related services
- 71314300 - Energy-efficiency consultancy services
- 71400000 - Urban planning and landscape architectural services
- 71500000 - Construction-related services
- 71600000 - Technical testing, analysis and consultancy services
- 71700000 - Monitoring and control services
- 71800000 - Consulting services for water-supply and waste consultancy
- 71900000 - Laboratory services
- 79993000 - Building and facilities management services
- 79993100 - Facilities management services
two.2.3) Place of performance
NUTS codes
- UKH17 - Breckland and South Norfolk
- UKH12 - Cambridgeshire CC
- UKH11 - Peterborough
- UKH14 - Suffolk
- UKH16 - North and West Norfolk
- UKH15 - Norwich and East Norfolk
Main site or place of performance
Breckland and South Norfolk,Cambridgeshire CC,Peterborough,Suffolk,North and West Norfolk,Norwich and East Norfolk
two.2.4) Description of the procurement
The works and services will comprise all types of Construction works and services, including design and other services as required to design, develop and construct the works. The specific works and services that may be procured under the framework cannot be clearly defined at this stage, however the nature and types of works that may be required may include those services identified by CPV code on or in connection with any land or property and related asset owned, rented, leased or developed by any of the public sector bodies eligible to use the framework, or on property or related assets in which any of the public sector bodies may have an interest at the time or prospectively and may include projects in the following sectors amongst others: education, housing, blue light, health, offices, transport, military, industrial and commercial buildings and other public sector operational buildings and establishments.
All contract performance will be monitored using a set of comprehensive performance indicators. Works and Services shall be delivered by the contractor and their supply chain. All works will be performed in accordance with the framework agreement and a delivery agreement executed in accordance with this agreement. Individual commissions called off under the framework may be as little as 0 GBP up to 7,500,000 GBP.
Bidders applying for this Lot were required to have a minimum annual turnover of 10,000,000 GBP.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 80
Cost criterion - Name: Price / Weighting: 20
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: Yes
Identification of the project
Some call-offs from this framework may be subject to the requirements of European/UK funding, Therefore, the framework delivery partner will need to comply with the funding requirements.
Section four. Procedure
four.1) Description
four.1.1) Type of procedure
Restricted procedure
four.1.3) Information about a framework agreement or a dynamic purchasing system
The procurement involves the establishment of a framework agreement
four.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: Yes
four.2) Administrative information
four.2.1) Previous publication concerning this procedure
Notice number: 2021/S 000-020003
Section five. Award of contract
Contract No
1
Lot No
1
Title
North West
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 1
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Jeakins Weir Limited
Uppingham House, Lawford Road
Rugby, Warwickshire
CV21 2UU
Country
United Kingdom
NUTS code
- UKG1 - Herefordshire, Worcestershire and Warwickshire
National registration number
01095682
The contractor is an SME
Yes
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £150,000,000
Total value of the contract/lot: £150,000,000
Section five. Award of contract
Contract No
2
Lot No
2
Title
North West
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 1
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Stepnell Limited
Stepnell House, Lawford Road,
Rugby, Warwickshire
CV21 2UU
Country
United Kingdom
NUTS code
- UKG1 - Herefordshire, Worcestershire and Warwickshire
National registration number
00402934
The contractor is an SME
No
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £150,000,000
Total value of the contract/lot: £150,000,000
Section five. Award of contract
Contract No
3
Lot No
3
Title
North East
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
G F Tomlinson Building Limited
Tomlinson House, Duffield Road, Little Eaton
Derby, Derbyshire
DE21 5DR
Country
United Kingdom
NUTS code
- UKF1 - Derbyshire and Nottinghamshire
National registration number
02332956
The contractor is an SME
Yes
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £150,000,000
Total value of the contract/lot: £150,000,000
Section five. Award of contract
Contract No
4
Lot No
4
Title
North East
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Lindum Group Limited
Station Road, North Hykeham
Lincoln, Lincolnshire
LN6 3QX
Country
United Kingdom
NUTS code
- UKF3 - Lincolnshire
National registration number
01236338
The contractor is an SME
No
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £150,000,000
Total value of the contract/lot: £150,000,000
Section five. Award of contract
Contract No
5
Lot No
5
Title
South West
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Ashe Construction Limited
Ashe House, Cooks Way
Hitchin, Herts
SG4 0JE
Country
United Kingdom
NUTS code
- UKH23 - Hertfordshire
National registration number
02373535
The contractor is an SME
No
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £37,500,000
Total value of the contract/lot: £37,500,000
Section five. Award of contract
Contract No
6
Lot No
6
Title
South West
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Conamar Building Services Limited
29-31 Orchard Road
Stevenage, Hertfordshire
SG1 3HE
Country
United Kingdom
NUTS code
- UKH23 - Hertfordshire
National registration number
02898417
The contractor is an SME
Yes
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £37,500,000
Total value of the contract/lot: £37,500,000
Section five. Award of contract
Contract No
7
Lot No
7
Title
South East
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Clegg Construction Limited
Bishops House, 4, 2 High Pavement, The Lace Market
Nottingham, Nottinghamshire
NG1 1HN
Country
United Kingdom
NUTS code
- UKF14 - Nottingham
National registration number
00667598
The contractor is an SME
Yes
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £37,500,000
Total value of the contract/lot: £37,500,000
Section five. Award of contract
Contract No
8
Lot No
8
Title
South East
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
26 August 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 2
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 0
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
R G Carter Cambridge Limited
9-11 Drayton High Road
Norwich, Norfolk
NR8 6AH
Country
United Kingdom
NUTS code
- UKH15 - Norwich and East Norfolk
National registration number
03879910
The contractor is an SME
No
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £37,500,000
Total value of the contract/lot: £37,500,000
Section six. Complementary information
six.3) Additional information
The CPV codes stated are deemed to include, the category and subcategory codes below the CPV code stated, i.e. 45000000, 'Construction Work' is deemed to include 45200000, 'Works for complete or part construction and civil engineering work' and 45212000 'Construction work for buildings relating to leisure, sports, culture, lodging and restaurants' etc.
Lots 1 and 2 do not include Rutland. This has been listed due to NUTS code limitations. Rutland is instead included in Lots 3 and 4.
Lots 3 and 4 do not include Leicestershire. This has been listed due to NUTS code limitations. Leicestershire is instead included in Lots 1 and 2.
To view this notice, please click here:
https://www.delta-esourcing.com/delta/viewNotice.html?noticeId=717591383
GO Reference: GO-202298-PRO-20920715
six.4) Procedures for review
six.4.1) Review body
Scape Group Ltd
2nd Floor, East West building, Tollhouse Hill
Nottingham
NG1 5AT
Telephone
+44 1159583200
Country
United Kingdom
Internet address
six.4.2) Body responsible for mediation procedures
The High Court of England and Wales
Royal Courts of Justice, Strand
London
WC2A 2LL
Country
United Kingdom
six.4.3) Review procedure
Precise information on deadline(s) for review procedures
In accordance with the instructions as detailed in the tender documentation.