Section one: Contracting authority
one.1) Name and addresses
The Northern Ireland Courts and Tribunal Service
c/o CPD, 303 Airport Road West
BELFAST
BT3 9ED
Country
United Kingdom
NUTS code
UK - United Kingdom
Internet address(es)
Main address
https://www.justice-ni.gov.uk/topics/courts-and-tribunals
Buyer's address
https://www.finance-ni.gov.uk/topics/procurement
one.2) Information about joint procurement
The contract is awarded by a central purchasing body
one.4) Type of the contracting authority
Body governed by public law
one.5) Main activity
General public services
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
ID 4281736 - DoJ - NICTS - Supply and Delivery of Legal Subscription Titles
two.1.2) Main CPV code
- 22110000 - Printed books
two.1.3) Type of contract
Supplies
two.1.4) Short description
The Northern Ireland Courts and Tribunals Service, more specifically the Office of the Lady Chief Justice, has a primary role in supporting the work of the Judiciary, the efficient and effective functioning of the courts and the delivery of the administration of justice in Northern Ireland. One of the major support functions is providing a legal library and information service to all tiers of the Judiciary, legal support staff and court administrators. The Library and Information Service functions in a high profile and fast paced environment with a requirement to deliver ‘at speed’ and to ‘pre-empt’ knowledge needs where possible. Items may be required at short notice and delay in their receipt can effect delay in decision making, lead to greater financial cost and making incorrect or un-researched decisions leading to loss of confidence, criticism and reputational damage to the Judiciary. The Northern Ireland Courts and Tribunals Service (NICTS) is seeking to establish a contract for the supply and delivery of legal subscription titles in print and/or electronic format.
two.1.6) Information about lots
This contract is divided into lots: No
two.1.7) Total value of the procurement (excluding VAT)
Value excluding VAT: £600,000
two.2) Description
two.2.2) Additional CPV code(s)
- 22112000 - Textbooks
- 92511000 - Library services
- 92510000 - Library and archive services
- 75231100 - Law-courts-related administrative services
- 22211000 - Journals
- 22211100 - Official journals
two.2.3) Place of performance
NUTS codes
- UKN - Northern Ireland
two.2.4) Description of the procurement
The Northern Ireland Courts and Tribunals Service, more specifically the Office of the Lady Chief Justice, has a primary role in supporting the work of the Judiciary, the efficient and effective functioning of the courts and the delivery of the administration of justice in Northern Ireland. One of the major support functions is providing a legal library and information service to all tiers of the Judiciary, legal support staff and court administrators. The Library and Information Service functions in a high profile and fast paced environment with a requirement to deliver ‘at speed’ and to ‘pre-empt’ knowledge needs where possible. Items may be required at short notice and delay in their receipt can effect delay in decision making, lead to greater financial cost and making incorrect or un-researched decisions leading to loss of confidence, criticism and reputational damage to the Judiciary. The Northern Ireland Courts and Tribunals Service (NICTS) is seeking to establish a contract for the supply and delivery of legal subscription titles in print and/or electronic format.
two.2.5) Award criteria
Quality criterion - Name: Proposed Methodology / Weighting: 39
Quality criterion - Name: Contract Management / Contingency Arrangements / Weighting: 21
Cost criterion - Name: Percentage Discount Offered / Weighting: 30
Cost criterion - Name: Delivery Charge / Weighting: 10
two.2.11) Information about options
Options: Yes
Description of options
The initial contract period is 3 years followed by one optional extension period of up to 24 months.
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: No
Section four. Procedure
four.1) Description
four.1.1) Type of procedure
Open procedure
four.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: Yes
four.2) Administrative information
four.2.1) Previous publication concerning this procedure
Notice number: 2022/S 000-022476
Section five. Award of contract
Contract No
1
Title
Contract
A contract/lot is awarded: Yes
five.2) Award of contract
five.2.1) Date of conclusion of the contract
18 October 2022
five.2.2) Information about tenders
Number of tenders received: 3
Number of tenders received from SMEs: 1
Number of tenders received from tenderers from other EU Member States: 0
Number of tenders received from tenderers from non-EU Member States: 1
Number of tenders received by electronic means: 3
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor
Information withheld for security reasons
Information withheld for security reasons
Country
United Kingdom
NUTS code
- UK - United Kingdom
Internet address
https://www.finance-ni.gov.uk/topics/procurement
The contractor is an SME
Yes
five.2.4) Information on value of contract/lot (excluding VAT)
Initial estimated total value of the contract/lot: £600,000
Total value of the contract/lot: £600,000
Section six. Complementary information
six.3) Additional information
Please note that information relating to contractors engaged by the Northern Ireland Department of Justice, and associated bodies is not published in any publicly accessible forum or publication. This is to protect such contractors, whose security and safety could be threatened by dissident terrorist organisations still active in Northern Ireland if their details became known. This is consistent with Regulation 50(6)(a). . . The estimated contract value is a broad estimate only and includes additional quantum for unforeseen demand and to future proof for additional potential. There is no guarantee of any level of business under this contract. The estimate is not deemed to be a condition of contract nor a guarantee of minimum demand or uptake. No compensation will be payable to a contractor should the actual demand be less than that stated. The contractor’s performance on this contract will be managed as per specification and regularly monitored. Contractors not delivering on contract requirements is a serious matter. It means the public purse is not getting what it is paying for. If a contractor fails to reach satisfactory levels of contract performance they will be given a specified time to improve. If, after the specified time, they still fail to reach satisfactory levels of contract performance, the matter will be escalated to senior management in Construction and Procurement Delivery for further action. If this occurs and their performance still does not improve to satisfactory levels within the specified period, it may be regarded as an act of grave professional misconduct and they may be issued with a notice of written warning and notice of unsatisfactory performance and this contract may be terminated. The issue of a notice of written warning and notice of unsatisfactory performance will result in the contractor being excluded from all procurement competitions being undertaken by Centres of Procurement Expertise on behalf of bodies covered by the Northern Ireland Procurement Policy for a period of up to 3 years from the date of issue of the notice..
six.4) Procedures for review
six.4.1) Review body
The UK does not have any special review body with responsibility for appeal/mediation procedures
The UK does not have any special review body with responsibility for appeal/mediation procedures
Country
United Kingdom
six.4.2) Body responsible for mediation procedures
The UK does not have any special review body with responsibility for appeal/mediation procedures
The UK does not have any special review body with responsibility for appeal/mediation procedures
Country
United Kingdom
six.4.3) Review procedure
Precise information on deadline(s) for review procedures
The UK does not have any special review body with responsibility for appeal/mediation procedures in public procurement competitions. Instead, any challenges are dealt with by the High Court, Commercial Division, to which proceedings may be issued regarding alleged breaches of the Public Contracts Regulations (as amended) 2015..