Section one: Contracting authority/entity
one.1) Name and addresses
Hywel Dda University Health Board
Ty Gorwel, Building 14, St David’s Park, Job's Well Road
Carmarthen
SA31 3BB
Contact
Lewis Wells
Country
United Kingdom
NUTS code
UK - United Kingdom
Internet address(es)
Main address
Buyer's address
https://www.sell2wales.gov.wales/search/Search_AuthProfile.aspx?ID=AA79805
one.4) Type of the contracting authority
Body governed by public law
one.5) Main activity
Health
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
Installation of Additional Treatment Spaces GGH AVH
Reference number
HDD-VEAT-21-03
two.1.2) Main CPV code
- 45220000 - Engineering works and construction works
two.1.3) Type of contract
Works
two.1.4) Short description
NHS Wales Shared Services Partnership on behalf on Hywel dda University Local Health Board wish to inform the market that they intend to award a contract toto progress with works at Glangwili Emergency Department and Amman Valley Hospital
At Glangwili the works will enable the conversion of an existing play area into treatment space for 3 patients. The works being undertaken here will assist in ensuring that patient flows can be maintained as the UHB heads into the winter months and enable the UHB to progress it’s restart and recovery process.
The works in Amman Valley Hospital will create 3 additional consultation rooms for the Ophthalmology Team. This will assist the UHB to progress its Planned Cared Recovery for the Ophthalmology services. The additional rooms will assist in the drive to reduce the current referral to treatment waiting times for Ophthalmology patients.
The Hywel Dda University Health Board (HDdUHB) has received additional capital funding from Welsh Government in 2021/22 to deliver scheme to enable Restart and Recovery following COVID-19
The bid was developed using cost survey information and identifying the priority to deal with COVID-19 issues across all areas of the Estate.
This programme of prioritisation of works has been agreed by the HDdUHB as appropriate investment.
two.1.6) Information about lots
This contract is divided into lots: No
two.1.7) Total value of the procurement (excluding VAT)
Value excluding VAT: £147,894.37
two.2) Description
two.2.2) Additional CPV code(s)
- 45215000 - Construction work for buildings relating to health and social services, for crematoriums and public conveniences
two.2.3) Place of performance
NUTS codes
- UKL24 - Powys
two.2.4) Description of the procurement
NHS Wales Shared Services on behalf of Hywel Dda University Health Board wish to inform the market that they intend to award a contract to TR Jones (Betws) Ltd for the supply and Installation of Additional Treatment Spaces GGH AVH, the works must be completed by 31st March 2022.
They are the appointed contractor for the BGH MRI and Enlli Ward Project competitively tendered previously. The specification of the work undertaken previously will be of a similar specification to those now required:
Contractors’ preliminaries & general conditions to be based on a direct equivalent to the BGH MRI Project
Labour costs to be based where applicable on those used on the BGH MRI and Enlli Ward Project
Mechanical & Electrical sub-contractors for BGH MRI and Enlli Ward Project will be utilised
Covid-19 impact costs will be aligned to latest tenders received
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: No
Section four. Procedure
four.1) Description
four.1.1) Type of procedure
Award of a contract without prior publication of a call for competition in the cases listed below
- The procurement falls outside the scope of application of the regulations
Explanation:
Hywel Dda University Health Board wish to urgently commence work for the Installation of Additional Treatment Spaces GGH AVH, to assist with the health boards treatment targets. The health board wishes to appoint TR Jones (Betws) Ltd to undertake this work.
The impact of not proceeding is that we will not improve the patient flow issues in the Emergency Department (ED) in Glangwili. Patients will experience delays in accessing the appropriate treatments in a timely manner. The impact of patient flow in ED will also have a knock-on impact on ambulance waiting times.
Will not deliver a reduction in the referral to treatment time for patients waiting for ophthalmology treatments in Amman Valley Hospital. COVID-19 has significantly increased the number of patients waiting for treatment. This project delivers an additional 3 rooms for treating patients
A 3rd wave in the pandemic has been predicted and the need have a safe environment in which to manage these patients in a cohorted location. Avoiding having patients treated in multiple locations and increasing the risk of nosocomial transmission.
Initially NWSSP procurement services conducted a tender exercise and the contractor has recently been awarded a contract for a similar contract at the Bronglais Hospital site following a competitive tender exercise and can complete the work by the required timescale.
four.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: Yes
Section five. Award of contract/concession
Contract No
HDD-VEAT-21-03
A contract/lot is awarded: Yes
five.2) Award of contract/concession
five.2.1) Date of conclusion of the contract
25 November 2021
five.2.2) Information about tenders
The contract has been awarded to a group of economic operators: No
five.2.3) Name and address of the contractor/concessionaire
T Richard Jones (Betws) Ltd
Betws Industrial Park, Foundry Road
Ammanford
SA182LS
Telephone
+44 1269591103
Country
United Kingdom
NUTS code
- UKL14 - South West Wales
The contractor/concessionaire is an SME
Yes
five.2.4) Information on value of contract/lot/concession (excluding VAT)
Total value of the contract/lot/concession: £147,894.37
Section six. Complementary information
six.3) Additional information
For all communication regarding this notice, please contact Lewis Wells at Lewis.wells2@wales.nhs.uk
(WA Ref:116191)
six.4) Procedures for review
six.4.1) Review body
High Court
Royal Courts of Justice, The Strand
London
WC2A 2LL
Telephone
+44 2079477501
Country
United Kingdom