Section one: Contracting authority
one.1) Name and addresses
Broxtowe Borough Council
Beeston
NOTTINGHAM
NG91AB
Telephone
+44 1159177777
Country
United Kingdom
Region code
UKF16 - South Nottinghamshire
Justification for not providing organisation identifier
Not on any register
Internet address(es)
Main address
one.3) Communication
The procurement documents are available for unrestricted and full direct access, free of charge, at
https://www.eastmidstenders.org/
Additional information can be obtained from the above-mentioned address
Tenders or requests to participate must be submitted electronically via
https://www.eastmidstenders.org/
Tenders or requests to participate must be submitted to the above-mentioned address
one.4) Type of the contracting authority
Regional or local authority
one.5) Main activity
General public services
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
BP1054 - Design and Build of Community Pavilion and Young People's Centre
Reference number
BP1054
two.1.2) Main CPV code
- 45210000 - Building construction work
two.1.3) Type of contract
Works
two.1.4) Short description
This is the shortlisting stage. Please ensure you read the procurement documentation especially PART ONE and provide the required information.
Broxtowe Borough Council (the Council) is undertaking this procurement to find a Contractor to finalise the design and build a Community Pavilion and Young People's Centre at Hickings Road, Recreation Ground in Stapleford, Nottingham. NG9 8PJ.
This project forms one of six core projects identified in the Stapleford Town Improvement Plan (TIP) and is funded by Towns Fund Deal.
The scope of the building works will comprise of the demolition of the existing changing pavilion and the construction of a new community leisure pavilion together with associated external works including installation of MUGA and replacement of skate park with community garden.
A new 11 a-side 3G football pitch is also planned on the site, and it is envisaged that this will be constructed concurrent to the building contract for the new pavilion, albeit the football pitch will be constructed by others. The successful contractor for the Pavilion will be expected to coordinate and work collaboratively with the 3G pitch contractor to ensure a safe working environment and coordination of site access and use.
Planning permission for the new pavilion has been approved (Reference 23/00051/REG3 dated 7th July 2023) which can be found: www.planning.broxtowe.gov.uk/ApplicationDetail?RefVal=23/00051/REG3
The works are planned to be let utilising either a JCT D&B 2016 or NEC4 Option A form of Building Contract on a design and build basis.
The Council invites the successful Contractor to take a novation of the Architect and Structural Engineer appointments. The successful Contractor may however propose alternatives in the tender (Stage 2) process. The Building Services Engineer will be retained by the Council.
The Contractor will be required to work collaboratively with the Client's professional team and the Clients' partners to coordinate the detailed design. It is envisaged that the works will commence Spring 2024 and take approximately 12 months. The project is funded by the Towns Deal and must be completed prior to April 2025.
The Council requires a competitive build price and would imagine maximum price of bids to be up to the value of £6.5m, but with potential to be lower.
NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.
two.1.5) Estimated total value
Value excluding VAT: £6,500,000
two.1.6) Information about lots
This contract is divided into lots: No
two.2) Description
two.2.2) Additional CPV code(s)
- 45200000 - Works for complete or part construction and civil engineering work
two.2.3) Place of performance
NUTS codes
- UKF1 - Derbyshire and Nottinghamshire
Main site or place of performance
Borough of Broxtowe
two.2.4) Description of the procurement
See II.1.4 . Short Description and Part 3 of the Selection Stage documents.
two.2.5) Award criteria
Price is not the only award criterion and all criteria are stated only in the procurement documents
two.2.7) Duration of the contract, framework agreement or dynamic purchasing system
Duration in months
12
This contract is subject to renewal
No
two.2.10) Information about variants
Variants will be accepted: No
two.2.11) Information about options
Options: No
two.2.14) Additional information
NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.
Section three. Legal, economic, financial and technical information
three.1) Conditions for participation
three.1.2) Economic and financial standing
Selection criteria as stated in the procurement documents
Section four. Procedure
four.1) Description
four.1.1) Type of procedure
Restricted procedure
four.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: Yes
four.2) Administrative information
four.2.2) Time limit for receipt of tenders or requests to participate
Date
2 October 2023
Local time
10:00am
four.2.3) Estimated date of dispatch of invitations to tender or to participate to selected candidates
27 October 2023
four.2.4) Languages in which tenders or requests to participate may be submitted
English
Section six. Complementary information
six.1) Information about recurrence
This is a recurrent procurement: No
six.4) Procedures for review
six.4.1) Review body
Broxtowe Borough Council
Council Offices, Beeston
Nottingham
NG10 5LS
Country
United Kingdom
six.4.3) Review procedure
Precise information on deadline(s) for review procedures
The contracting authority will incorporate a minimum 10 calendar day standstill period following electronic notification (minimum of 15 calendar days for any other means of communication) to tenderers of the award decision. This period allows unsuccessful tenderers to seek further debriefing from the contracting authority before the contract is entered into. If an appeal regarding the award of a contract has not been successfully resolved the Public Contracts Regulations 2015 (Si 2015 No 102) provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rules to take action in the High Court (England, Wales and Northern Ireland). Any such action must be brought promptly (generally within 3 months). Where a contract has not been entered into the Court may order the setting aside of the award decision or order the authority to amend any document and may award damages. If the contract has been entered into the Court may only award damages. The purpose of the standstill period referred to above is to allow parties to apply to the Courts to set aside the award decision before the contract is entered into.