Section one: Contracting authority
one.1) Name and addresses
Rotherham Metropolitan Borough Council
Riverside House, Main Street
Rotherham
S60 1AE
Contact
Toni Cox
Telephone
+44 1709334196
Country
United Kingdom
Region code
UK - United Kingdom
National registration number
GB173552264
Internet address(es)
Main address
Buyer's address
https://uk.eu-supply.com/ctm/Company/CompanyInformation/Index/104118
one.3) Communication
The procurement documents are available for unrestricted and full direct access, free of charge, at
https://uk.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=73686&B=UK
Additional information can be obtained from the above-mentioned address
Tenders or requests to participate must be submitted electronically via
https://uk.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=73686&B=UK
Tenders or requests to participate must be submitted to the above-mentioned address
one.4) Type of the contracting authority
Regional or local authority
one.5) Main activity
General public services
Section two: Object
two.1) Scope of the procurement
two.1.1) Title
Damp Proof Services
Reference number
22-013
two.1.2) Main CPV code
- 50000000 - Repair and maintenance services
two.1.3) Type of contract
Services
two.1.4) Short description
The contract covers attending to Council owned properties to conduct a damp survey following a referral from the CIC Team. Following a survey, the incumbent will supply a full detailed report (as set out in the Service Requirements) which details their findings and any remediation works required. Remediation costs will also be supplied. Once the CIC Team gives the incumbent authorisation to proceed with the works, the incumbent will be responsible for arranging access with the tenant, carrying out all the works in line with our Service Requirements as well as liaising with tenant at pre-commencement stage to ensure a smooth transition of works with minimal disruption to both the incumbent and the tenant. The incumbent will be responsible for all management, supervision and Health and Safety costs associated with each job.
two.1.5) Estimated total value
Value excluding VAT: £3,000,000
two.1.6) Information about lots
This contract is divided into lots: No
two.2) Description
two.2.2) Additional CPV code(s)
- 50000000 - Repair and maintenance services
two.2.3) Place of performance
NUTS codes
- UK - United Kingdom
two.2.4) Description of the procurement
The contract covers attending to Council owned properties to conduct a damp survey following a referral from the CIC Team. Following a survey, the incumbent will supply a full detailed report (as set out in the Service Requirements) which details their findings and any remediation works required. Remediation costs will also be supplied. Once the CIC Team gives the incumbent authorisation to proceed with the works, the incumbent will be responsible for arranging access with the tenant, carrying out all the works in line with our Service Requirements as well as liaising with tenant at pre-commencement stage to ensure a smooth transition of works with minimal disruption to both the incumbent and the tenant. The incumbent will be responsible for all management, supervision and Health and Safety costs associated with each job.
two.2.5) Award criteria
Quality criterion - Name: Quality / Weighting: 40
Quality criterion - Name: Social Value / Weighting: 20
Price - Weighting: 40
two.2.6) Estimated value
Value excluding VAT: £3,000,000
two.2.7) Duration of the contract, framework agreement or dynamic purchasing system
Start date
1 March 2024
End date
28 February 2027
This contract is subject to renewal
Yes
Description of renewals
1 x 12 month extension at the sole discretion of the Council
two.2.10) Information about variants
Variants will be accepted: No
two.2.11) Information about options
Options: No
two.2.13) Information about European Union Funds
The procurement is related to a project and/or programme financed by European Union funds: No
Section three. Legal, economic, financial and technical information
three.1) Conditions for participation
three.1.2) Economic and financial standing
Selection criteria as stated in the procurement documents
three.1.3) Technical and professional ability
Selection criteria as stated in the procurement documents
Section four. Procedure
four.1) Description
four.1.1) Type of procedure
Open procedure
four.1.8) Information about the Government Procurement Agreement (GPA)
The procurement is covered by the Government Procurement Agreement: Yes
four.2) Administrative information
four.2.2) Time limit for receipt of tenders or requests to participate
Date
9 February 2024
Local time
5:00pm
four.2.4) Languages in which tenders or requests to participate may be submitted
English
four.2.7) Conditions for opening of tenders
Date
9 February 2024
Local time
5:00pm
Section six. Complementary information
six.1) Information about recurrence
This is a recurrent procurement: No
six.4) Procedures for review
six.4.1) Review body
High Court
The Royal Courts of Justice, The Strand,
London
WC2A 2LL
Country
United Kingdom
six.4.2) Body responsible for mediation procedures
High Court
Royal Courts of Justice, The Strand
London
WC2A 2LL
Country
United Kingdom
six.4.3) Review procedure
Precise information on deadline(s) for review procedures
Precise information on deadline(s) for lodging appeals: The Contracting Authority will incorporate a minimum 10 calendar day standstill period at the point information on the award of the Contract is communicated to tenderers. Applicants who are unsuccessful shall be informed by the Contracting Authority as soon as possible after the decision has been made as to the reasons why the applicant was unsuccessful. If an appeal regarding the award of the contract has not been successfully resolved, the Public Contracts Regulations 2015 (as amended) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take legal action. Any such action must be brought within the applicable limitation period. Where a contract has not been entered into, the Court may order the setting aside of the award decision or order the Contracting Authority to amend any document and may award damages. If the Contract has been entered into, the Court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order the Contracting Authority to pay a fine, and/or order that the duration of the Contract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the Courts to set aside the award decision before the contract is entered into.
six.4.4) Service from which information about the review procedure may be obtained
High Court
The Royal Courts of Justice, The Strand,
London
WC2A 2LL
Country
United Kingdom